senior contracts manager

Parsons

<div>In a world of possibilities, pursue one with endless opportunities. Imagine Next!<br>
<p></p>
At Parsons, you can imagine a career where you thrive, work with exceptional people, and be yourself. Guided by our leadership vision of valuing people, embracing agility, and fostering growth, we cultivate an innovative culture that empowers you to achieve your full potential. Unleash your talent and redefine what&rsquo;s possible.<p></p><p><b><br>
Job Description:</b></p><p>
Parsons are seeking an experienced <b>Senior </b><b>Contracts Manager </b>to lead contract administration, procurement support, claims management, and commercial governance for a major airfield development project. This role ensures that all contractual matters are managed in accordance with project requirements, legal frameworks, and stakeholder expectations.</p><p></p><p>
The ideal candidate has 15 years of experience in contracts management within large-scale infrastructure, aviation, or complex civil works.</p><p></p><p><b>
What You'll Be Doing;</b></p><ul><li>
Manage pre- and post-contract activities including tendering, negotiations, and contract execution.</li><li>
Oversee contractual compliance, variations, claims, and commercial risks.</li><li>
Maintain contract records, notices, and correspondence.</li><li>
Evaluate contractor claims, extensions of time, and cost variations.</li><li>
Support dispute resolution, contract interpretation, and mitigation strategies.</li><li>
Ensure alignment with project budget and commercial controls.</li><li>
Act as the point of contact for contractual matters with contractors, consultants, and legal teams.</li><li>
Coordinate with planning, engineering, and finance to ensure contract alignment with progress.</li></ul><p></p><p><b>
What Required Skills You'll Bring;</b></p><p></p><ul><li>
Bachelor&rsquo;s degree in Quantity Surveying, Construction Management, Law, or related field.</li><li>
Minimum <b>15 years</b> in contract administration/management on large infrastructure projects.</li><li>
Strong experience with FIDIC and similar international conditions of contract.</li><li>
Excellent contract drafting, negotiation, and claims evaluation skills.</li><li>
Strong commercial, analytical, and communication abilities.</li><li>
Experience in aviation/airfield project contracts.</li><li>
MRICS, MCIOB, or equivalent professional certification.</li><li>
Knowledge of commercial management software (Aconex, SAP).</li></ul><p></p>
Parsons equally employs representation at all job levels no matter the race, color, religion, sex (including pregnancy), national origin, age, disability or genetic information.<p></p><p>
We truly invest and care about our employee&rsquo;s wellbeing and provide endless growth opportunities as the sky is the limit, so aim for the stars! Imagine next and join the Parsons quest&mdash;APPLY TODAY!</p><p></p><div>
Parsons is aware of fraudulent recruitment practices. To learn more about recruitment fraud and how to report it, please refer to https://www.parsons.com/fraudulent-recruitment/.</div></div>
<br><div><div><div>COMPETITIVE BENEFIT OFFERINGS</div></div><div><div><div><br>
Financial Wellness</div><div><br>
We care about your financial wellbeing. Parsons offers competitive pay and retirement plans to help you build wealth for the future while giving you the flexibility to diversify your investments.</div></div><div><div>
Work Life Harmony</div><div><br>
Balance in life is important and time away from the office is imperative to allow you to refresh and focus your attention on the things that matter to you. Parsons supports your time away by providing paid time off and paid flexible holidays.</div></div><div><div>
Career Development</div><div><br>
We are committed to fostering the personal and professional growth of our employees. Develop and advance yourself though our comprehensive training, educational and mentorship programs.</div></div><div><div><br>
Veteran Support</div><div><br>
We provide Industry leading benefits to support veterans and active-duty members to provide security for you and your family by offering robust leave and benefits; including paid active-duty military leave and paid time off when transitioning back to civilian life.</div></div><div><div>
Mind &amp; Body</div><div><br>
At Parsons we inspire healthier habits, heathier minds, and a healthier you through our wellness program. Participate in our weekly Meditation Mondays and Wellness Wednesdays. Wellness, at Parsons, is more than just your annual checkup.</div></div><div><div>
Health</div><div><br>
Health is not a one size fits all. At Parsons, we offer a robust Employee Assistance Program as well as comprehensive medical, dental and vision plans through large, national carriers with the choice of regional PPO, HDHP, or HMO networks.</div></div></div></div><p></p>

Senior Contracts Manager

Mace Group

<div><div>Mace combines construction expertise with consultancy to unlock potential in every person or project and redefine the boundaries of ambition. Our values shape the way we consult and define the people we want to join us on our journey.</div><div></div><p><br>
The project:</p><div>
 This is an opportunity to work on one of the largest programmes in Saudi Arabia. This unique project consists of major mixed-use development including sports facilities, entertainment, and arts along with all associated infrastructure.<br>
Mace is one of the delivery partners requiring high-calibre and experienced professionals to lead integrated teams throughout each phase of the project.</div><p></p><p><br>
You&rsquo;ll be responsible for:</p><ul><li><div>
Prepares and administers construction contracts, including documents, warranties, bonds, licenses, variations, valuations, and certification through to final accounts and completion.</div></li><li><div>
Provides advice on contract terms, execution, practical completion, defects completion, and compliance with submission and approval requirements.</div></li><li><div>
Measures, values, and agrees work progress, variations, and contractor payments in line with contractual provisions.</div></li><li><div>
Maintains rigorous cost control, identifying and managing all costs arising from design changes, contract awards, construction activities, and client charges.</div></li><li><div>
Prepares accurate financial reports for clients, issued in the required format and frequency.</div></li><li><div>
Participates in the assessment of contractor and subcontractor claims for delay and additional costs, providing balanced commercial advice.</div></li><li><div>
Leads and manages a team, driving performance, technical development, coaching, and continuous improvement in systems and processes.</div></li><li><div>
Manages internal and external stakeholders collaboratively, supporting net zero carbon objectives through proactive identification and management of emissions and reductions.</div></li></ul><p></p><p><br>
You&rsquo;ll need to have:</p><ul><li><div>
Degree in quantity surveying/cost management (or equivalent).</div></li><li><div>
Professional membership or working towards i.e. MRICS/RICS, or equivalent demonstrable professional or personal development.</div></li><li><div>
Developed commercial and financial acumen.</div></li><li><div>
Knowledge of value engineering, life cycle costing, contract law and contractual frameworks relating to construction.</div></li><li><div>
Developing experience of managing relationships with key stakeholders.</div></li></ul><p></p><div><br>
Our values</div><div></div><div><br>
Safety first - Going home safe and well: We champion a safe, diverse and inclusive working environment, understanding the importance of wellbeing in every team.</div><div></div><div><br>
Client focus - Deliver on our promise: We own the quality of deliverables, strategic outcomes and build long term relationships with our clients.</div><div></div><div><br>
Integrity - Always do the right thing: We influence positive outcomes within our industry, while always aligning with our compliance obligations.</div><div></div><div><br>
Create opportunity - For our people to excel: We champion a continuous improvement culture throughout all activities, inspiring our people and teams to develop.</div><div><br>
Mace is an inclusive employer and welcomes interest from a diverse range of candidates. Even if you feel you do not fulfil all the criteria, please apply as you may still be the best candidate for this role or another role within our organisation.<br>
<br>
We are also open to discussing part time, flexible, and hybrid working options if suitable with-in the role</div><p>
#LI-Onsite</p></div>

HanmiGlobal Saudi

<div><p>As a <b>Senior Quantity Surveyor</b> at HanmiGlobal Saudi, you will be pivotal in managing all aspects of the costs and contracts of construction projects. You will provide cost advice, prepare estimates, and ensure that projects are completed within budget and on time. Your expertise will help in maximizing project value and minimizing financial risk.</p><b>
Key Responsibilities</b><ul><li>
Prepare and submit promptly the detailed cost estimates for all phases of projects.</li><li>
Analyze project specifications, drawings, and bills of quantities for tendering purposes.</li><li>
Negotiate contracts and ensure compliance with contractual obligations.</li><li>
Manage variations and claims, evaluating the impact of change orders.</li><li>
Provide financial forecasts and maintain detailed financial reports throughout the project lifecycle.</li><li>
Collaborate with project managers and stakeholders to optimize the project's financial performance.</li><li>
Monitor and report on cash flow and financial aspects of the project.</li><li>
Lead and mentor junior quantity surveyors and provide training as necessary.</li><li>
Assist in risk management and help develop mitigation strategies.</li><li>
Ensure adherence to health and safety regulations during all stages of project execution.</li></ul><br>
<b>
Requirements</b><br>
<ul><li>
Bachelors degree in Quantity Surveying, Construction Management, or a related field.</li><li>
Minimum 8 years of experience in quantity surveying within the construction industry.</li><li>
Proficiency in cost management software and Microsoft Office Suite.</li><li>
Strong negotiation and analytical skills.</li><li>
Excellent communication and teamwork abilities.</li></ul></div>

Senior Quantity Surveyor/Contract Manager

Hill International

<div><p>In this role, you will support the full contract lifecycle, including drafting, review, negotiation, and compliance management. You will work closely with internal teams and external stakeholders to ensure contract terms align with company policies, monitor deliverables and timelines, and address any risks or issues. The role also involves conducting audits, tracking contract performance, and providing insights to improve processes and ensure smooth and compliant contract execution.</p></div>
<br><div><ul><li>Support managing the entire contract lifecycle, including drafting, negotiation, implementation, and compliance.
</li><li>Review and analyze contract terms and conditions to identify potential risks and propose appropriate solutions.
</li><li>Collaborate with internal teams, including legal, finance, and project management, to ensure contract terms are aligned with company policies and objectives.
</li><li>Develop and maintain strong relationships with clients, suppliers, and subcontractors to ensure smooth contract execution.
</li><li>Monitor and track contract deliverables, milestones, and deadlines to ensure timely completion.
</li><li>Identify and resolve any contract-related issues or disputes in a timely and efficient manner.
</li><li>Conduct regular contract audits to ensure compliance with contractual obligations and company policies.
</li><li>Prepare and present reports on contract performance and provide recommendations for improvement.
</li><li>Stay updated with industry trends and best practices in contract management to continuously improve processes and systems.
</li><li>Informs themselves of the relevant Quality, Environmental, Safety and Occupational Health Policies, Manuals and Procedures in place within Hill International, and ensures continued compliance with these requirements while employed by Hill.
</li><li>Perform other duties as assigned by the line manager/supervisor.</li></ul></div>
<br><div><ul><li>Bachelor in engineering from an accredited university.
</li><li>Minimum 15 years&rsquo; experience in contracts management including overall responsibility for contract management on large-scale projects.
</li><li>Experience with the Kingdom of Saudi Arabia procurement law .
</li><li>Demonstrated experience in pricing, contract law, contract drafting, administration and negotiation of change orders, effective correspondence, planning and scheduling.
</li><li>Thorough knowledge of prime contracts management administration as well as (sub) contract formation and administration, execution office and field procedures and documents relating to a multi-discipline construction project.
</li><li>Excellent verbal and written communication skills in both Arabic and English.</li></ul></div>

Senior Contracts Management Engineer (HQ)

WebBeds

<div><p><b>About WebBeds</b></p>
<p>
Launched in 2013, WebBeds is a global marketplace for the travel trade, providing powerful distribution solutions that make selling and buying travel products easier. It sources accommodation and destination services from travel suppliers, aggregates and merchandises that content in the WebBeds platform, then distributes it to its global network of travel trade buyers, who sell to the travelling public.</p>
<p>
Hotels and other suppliers - global and regional hotel chains, independent hotels, apartments, resorts, attractions, transfer and sightseeing companies and more - can sell their products to a global network of online and offline travel buyers through robust solutions that provide greater inventory control to simplify distribution, and leverage WebBeds enhanced analytics to inform inventory optimisation choices &ndash; saving costs and increasing revenue.</p>
<p>
Travel buyers - online travel agencies, retail travel agents, corporate travel managers, tour operators, wholesalers, tourism boards, super apps, DMC&rsquo;s, group providers, airlines and more - can integrate the hundreds of thousands of hotels and ground services in the WebBeds marketplace through simple and seamless API connectivity, or they can search, shop and book online through one of WebBeds trade only booking sites.</p>
<p>
WebBeds operates globally through four geographic regions &ndash; Europe, Asia Pacific, MEA (Middle East and Africa) and Americas - with over 1,900 travel professionals working in 120 cities across 50 countries worldwide.</p>
<p>
Find out more about the WebBeds business at www.webbeds.com
</p><p>WebBeds is a travel brand of the Web Travel Group (ASX: WEB).</p><p></p><p><b><br>
In this role you will :</b></p>
<p>
As a Contracts Manager at WebBeds, you will play a critical role in securing competitive hotel contracts for</p>
<p>
the regions under your remit. Your efforts will contribute to achieving the company's KPIs, including securing the ideal mix of hotels, competitive pricing, availability, and margins. You will have full ownership and are responsible for all revenue streams coming into the destination that you manage.</p><p></p><p><b><br>
Key responsibilities</b></p>
<ul><li>
Negotiate and secure contracts with hotels in your allocated regions to meet the company&rsquo;s KPIs, including:</li><li><ul><li>
Number and mix of hotels.</li><li>
Competitive pricing and availability.</li><li>
Revenue performance of hotels in your portfolio.</li></ul></li><li>
Develop and maintain relationships with hotel partners, ensuring alignment with WebBeds&rsquo; strategic goals.</li><li>
Regularly review the performance of contracted hotels, addressing issues related to pricing, availability, or quality.</li><li>
Conduct market research to identify opportunities for expansion and ensure competitiveness in assigned regions.</li><li>
Collaborate with the regional leadership to develop and implement effective contracting strategies.</li><li>
Monitor and analyse destination performance metrics to ensure continuous improvement and alignment with company goals.</li></ul><p></p><p><b><br>
The skills we would love to see in your suitcase!</b></p>
<ul><li>
Proven experience in hotel account management or a similar role in the travel industry.</li><li>
Strong knowledge of the assigned region(s) and its hospitality market dynamics.</li><li>
Demonstrated ability to meet revenue targets in a competitive environment.</li><li>
Experience in building and managing relationships with hotel partners.</li><li>
Familiarity with online distribution platforms, APIs, or cloud-based systems is a plus.</li><li>
Excellent analytical and organizational skills.</li><li>
Fluency in English; additional language skills relevant to the assigned regions are highly desirable.</li><li>
Negotiation Skills: Ability to secure favourable terms while maintaining strong relationships with partners.</li><li>
Market Knowledge: Deep understanding of the travel and accommodation market in assigned regions</li><li>
Analytical Thinking: Capable of evaluating market trends and performance data to make informed decisions.</li><li>
Communication: Strong interpersonal and written skills for liaising with internal and external stakeholders.</li><li>
Results Orientation: Demonstrated ability to meet or exceed performance targets in a fast-paced environment.</li><li>
Problem-Solving: Proactive and resourceful in overcoming challenges and identifying innovative solutions.</li><li>
Contracting experience gained with the hotel industry.</li><li>
Able to develop and maintain strong and trusting relationship with hoteliers.</li><li>
Educated to degree level of equivalent or equivalent professional qualification.</li><li><b>
Minimum 2 years contracting experience in hotel industry (OTAs, Bed banks, Tour Operators).</b></li><li>
Understanding of current contracting landscape (dynamic and static models).</li><li>
Highly accurate with excellent attention to detail.</li><li>
Well-developed written and verbal communication skills.</li><li>
Professional fluency in <b>English and Arabic </b>is mandatory.</li><li>
Able to work well under pressure and meet strict deadlines.</li><li>
A solid working knowledge of Microsoft Word, Excel, and Outlook.</li></ul><p></p><p><b><br>
Why choose us as your next destination?</b></p>
<p>
We are super proud of our dedicated team of friendly, energetic &amp; passionate professionals. Our people are key to the success of our business &amp; everybody at WebBeds has their own unique role to play as we continue to drive the company forward.</p>
<p>
Over 50 different languages are spoken by our workforce, but whether working from offices in Dubai or London or out in the field in Johannesburg or Buenos Aires, we all share the common goal to take pride in what we do &amp; to deliver our partners with unbeatable service &amp; support.</p>
International highly skilled group of experts from all around the globe<ul>
Dynamic environment with the chance to grow, influence &amp; impact change
Disruptive, fast-growing market leader within travel &amp; endless possibilities
Culture built on collaboration empowerment and innovation</ul><p></p><p><br>
Find out more about the WebBeds business at www.webbeds.com - <b>#LI-Hybrid</b></p></div>

Contracts Manager Saudi Arabia

<div>In a world of possibilities, pursue one with endless opportunities. Imagine Next!<br>
<p></p>
At Parsons, you can imagine a career where you thrive, work with exceptional people, and be yourself. Guided by our leadership vision of valuing people, embracing agility, and fostering growth, we cultivate an innovative culture that empowers you to achieve your full potential. Unleash your talent and redefine what&rsquo;s possible.<p></p><p><b><br>
Job Description:</b></p><div><div><p>
Parsons is looking for an amazingly talented <b>Assistant Contracts Manager</b><b> </b>to join our team! In this role you will get to <b>be part of a major Program Management Office in Riyadh</b>.</p></div><p></p><div><p><b><br>
What You'll Be Doing:</b></p></div><div><ul><li><p>
Checking and reporting on designer, contractor and associated parties compliance with the contract and progress of works.</p></li></ul></div><div><ul><li><p>
Coordination with site team to ascertain contractual and practical measures to ensure compliance with requirements. Advice on specific requirements of the contract and performance in accordance therewith.</p></li></ul></div><div><ul><li><p>
Assessing contractual implications of site decisions and optimization of practical contract conditions</p></li></ul></div><div><ul><li><p>
Review of contractual correspondence from and to contractors and consultants</p></li></ul></div><div><ul><li><p>
Maintenance of trackers for securities, early warnings and claims</p></li></ul></div><div><ul><li><p>
Advising on entitlement in respect of variations and claims and recommending appropriate solutions</p></li></ul></div><div><ul><li><p>
Review of contract documentation in respect of consultants and contractors</p></li></ul></div><div><ul><li><p>
Involvement in and management of performance reviews in respect of consultants and contractors</p></li></ul></div><div><ul><li><p>
Advising on compliance with Tender and Procurement Law</p></li></ul></div><div><ul><li><p>
Assessment of Technical and Financial tender proposals</p></li></ul></div><div><ul><li><p>
Ensuring that changes are managed in compliance with the contract provisions</p></li></ul></div><div><ul><li><p>
Recommending improvements in contract management processes in alignment with Client protocols</p></li></ul></div><div><ul><li><p>
Advising on entitlement and valuation of time and cost claims</p></li></ul></div><div><ul><li><p>
Maintaining a working relationship with Design, Construction, Engineering, Procurement and Legal Management to facilitate organizational interfaces</p></li></ul></div><div><ul><li><p>
Liaison with the PMO Cost Management team, in the management of Change Orders.</p></li></ul></div><div><ul><li><p>
Agreeing valuations methods of reimbursement with client and Parsons representatives.</p></li></ul></div><div><ul><li><p>
Liaison and coordination of agreement on valuations with Contractors.</p></li></ul></div></div><div><div><ul><li><p>
Managing directives and variations, reviewing client requirements, assessing implications negotiation of omissions or extra costs, coordination and reporting on the contractual implications of other parties engaged with the works.</p></li></ul></div><div><ul><li><p>
Final Accounts management including preparation, submission and agreement with client/Consultant and similarly with the respective subcontractors.</p></li></ul></div><p></p><div><p><b><br>
What Required Skills You'll Bring:</b></p></div><div><ul><li><p>
Minimum 10 years of experience within the construction industry</p></li></ul></div><div><ul><li><p>
Experience in a commercial / contract role with Grade A contractor is desirable</p></li></ul></div><div><ul><li><p>
Having sufficient years of experience involving in Infrastructure Works / fields</p></li></ul></div><div><ul><li><p>
Technically sound with sufficient knowledge on construction methodology</p></li></ul></div><div><ul><li><p>
Bachelor's Degree in Quantity Surveying / Construction Management / Construction Technology / Civil Infrastructure Engineering / Architecture</p></li></ul></div><div><ul><li><p>
Good in interpreting contractual terms and understand the legal implications of construction project</p></li></ul></div><div><ul><li><p>
Analytical thinking, able to apply logic / rationale and impartial judgement on any prepared contractual communication correspondences</p></li></ul></div><div><ul><li><p>
Good proficiency in English language and writing skills</p></li></ul></div><div><ul><li><p>
Knowledge of principles of measurement</p></li></ul></div><div><ul><li><p>
Sound understanding of the application of legal principles</p></li></ul></div><div><ul><li><p>
Membership of a Chartered organization such as RICS is desirable</p></li></ul></div><p></p><div><p><b><br>
What Desired Skills You'll Bring:</b></p></div><div><ul><li><p>
Understand contractual terms &amp; conditions, process, scope of work, compensation schedule, project milestones/critical path and contract administration requirement.</p></li></ul></div><div><ul><li><p>
Sound knowledge on contractual terms and conditions, FIDIC and others</p></li></ul></div><div><ul><li><p>
Experience in a commercial / contract role with Grade A contractor is desirable</p></li></ul></div></div><div><div><ul><li><p>
Client facing</p></li></ul></div><div><ul><li><p>
Attentive to details, meticulous planning and organizing</p></li></ul></div><div><ul><li><p>
Possess general management skills such as the ability to act with integrity, use sound judgement, drive for results and focus</p></li></ul></div></div><p></p>
Parsons equally employs representation at all job levels no matter the race, color, religion, sex (including pregnancy), national origin, age, disability or genetic information.<p></p><p>
We truly invest and care about our employee&rsquo;s wellbeing and provide endless growth opportunities as the sky is the limit, so aim for the stars! Imagine next and join the Parsons quest&mdash;APPLY TODAY!</p><p></p><div>
Parsons is aware of fraudulent recruitment practices. To learn more about recruitment fraud and how to report it, please refer to https://www.parsons.com/fraudulent-recruitment/.</div></div>
<br><div><div><div>COMPETITIVE BENEFIT OFFERINGS</div></div><div><div><div><br>
Financial Wellness</div><div><br>
We care about your financial wellbeing. Parsons offers competitive pay and retirement plans to help you build wealth for the future while giving you the flexibility to diversify your investments.</div></div><div><div>
Work Life Harmony</div><div><br>
Balance in life is important and time away from the office is imperative to allow you to refresh and focus your attention on the things that matter to you. Parsons supports your time away by providing paid time off and paid flexible holidays.</div></div><div><div>
Career Development</div><div><br>
We are committed to fostering the personal and professional growth of our employees. Develop and advance yourself though our comprehensive training, educational and mentorship programs.</div></div><div><div><br>
Veteran Support</div><div><br>
We provide Industry leading benefits to support veterans and active-duty members to provide security for you and your family by offering robust leave and benefits; including paid active-duty military leave and paid time off when transitioning back to civilian life.</div></div><div><div>
Mind &amp; Body</div><div><br>
At Parsons we inspire healthier habits, heathier minds, and a healthier you through our wellness program. Participate in our weekly Meditation Mondays and Wellness Wednesdays. Wellness, at Parsons, is more than just your annual checkup.</div></div><div><div>
Health</div><div><br>
Health is not a one size fits all. At Parsons, we offer a robust Employee Assistance Program as well as comprehensive medical, dental and vision plans through large, national carriers with the choice of regional PPO, HDHP, or HMO networks.</div></div></div></div><p></p>

Assistant Contracts Manager

Siemens

<div></div><div><p>Siemens Mobility (SMO) is the world&rsquo;s leading provider of mobility solutions that enable the efficient, safe, and environmentally friendly transport of people and goods&mdash;helping to improve the quality of everyday life for millions worldwide.</p>
<p>
Motivated by innovation, we develop intelligent solutions for the growing digitalization of the transport sector. Our offerings include rail vehicles, rail automation, road traffic management systems, rail electrification, and services.</p>
<p>
In Saudi Arabia, Siemens Mobility is at the forefront of shaping the future of transportation by delivering cutting-edge rail and metro solutions in alignment with Vision 2030. Our advanced automation and signaling solutions are powering the Riyadh Metro, the longest driverless metro in the world, spanning a combined length of 176 kilometers, is set to revolutionize mobility in the capital by reducing road congestion and enhancing connectivity across the city.</p>
<p>
Today, we are recruiting for a <b>Junior Contract Administrator </b>to join our team in Saudi Arabia. This is an excellent career opportunity for professionals looking to join a truly international team in one of the biggest projects of Siemens Mobility.<br>
<br>
<b>What are my responsibilities?</b></p>
<ul>
<li>Administer the contract in accordance with its terms and conditions, monitor compliance with contractual obligations, milestones, and deliverables, and ensure proper documentation and record-keeping to preserve contractual entitlements</li>
<li>Maintain registers and trackers for notices, variations, claims, instructions, warranties, and correspondence, while monitoring all incoming and outgoing communication with the Main Contractor and tracking response timelines to ensure compliance with notice provisions</li>
<li>Ensure timely preparation and issuance of contractual notices (delay, variation, disruption, access constraints, change in law, etc.) and prevent waiver of contractual rights</li>
<li>Monitor delays arising from late handover of rooms, buildings, or track access and incomplete civil or MEP works, assist in issuing formal notifications for access restrictions or interference, and compile substantiation records including site logs, possession records, and coordination minutes</li>
<li>Assist in reviewing and evaluating variation instructions, maintain a variation register and approval status, support preparation of cost and time impact assessments, and ensure all instructed changes are formally recorded in accordance with contract provisions</li>
<li>Assist in preparation and submission of Extension of Time (EOT), prolongation, disruption, and acceleration or re-sequencing claims, coordinate with the planning team on critical path impacts, and compile supporting documents such as approval delays, interface failures, testing disruptions, and restricted access records</li>
<li>Monitor certification status and payment timelines and assist in issuing formal notifications in case of delays in payment application certification or invoice settlement</li>
<li>Monitor design milestones (Preliminary, 90%, and 100% Final Design), set up trackers for response timelines of design reviews and submissions, and record design changes and associated impacts arising from external interface issues</li>
<li>Monitor changes in applicable laws, regulations, technical standards, and customs tariffs, assess contractual and commercial implications, and assist in preparing formal notifications for change-in-law or regulatory impact claims</li>
</ul>
<p><b>What do I need to qualify for this job?</b></p>
<ul>
<li>Bachelor&rsquo;s degree in Quantity Surveying, Contracts Management, Engineering, Law, or a related discipline</li>
<li>Fluent in English and Arabic</li>
<li>Good communication (written and oral) and negotiation skills</li>
<li>Familiarity with contract administration under EPC environments</li>
<li>Ability to work in a highly competitive market with challenging targets and timelines</li>
</ul>
<p><b>What else do I need to know?</b></p>
<p>
As a world leader in developing and producing the most advanced technologies, we improve lives and further human achievements worldwide, while also protecting the climate - all thanks to our employees. Working with us, you have the foundation to develop personally and professionally. We give you the chance to do something significant, that benefits society and human progress. We give you the chance to create a difference.</p>
<p>
At Siemens we are always challenging ourselves to build a better future. We need the most innovative and diverse Digital Minds to develop tomorrow &lsquo;s reality. Find out more about the Digital world of Siemens here: www.siemens.com/careers/digitalminds</p>
<p>
Diversity at Siemens is our source of creativity and innovation. Having different types of talent and experiences makes us more ambitious and better prepared to respond successfully to the demands of the Society. Therefore, we value the candidates that reflect the Diversity that we enjoy in our Company. Please find more information at www.siemens.com</p></div>

Junior Contract Administrator (Saudi National) @Siemens Mobility KSA

Explore 1090+ Senior contracts manager in Riyadh this April. Find roles across top companies and apply now to boost your career.

1090 senior contracts manager jobs In Riyadh

Senior Contracts Manager

Senior Contracts Manager

Senior Quantity Surveyor/Contract Manager

Senior Contracts Management Engineer (HQ)

Contracts Manager Saudi Arabia

Assistant Contracts Manager

Junior Contract Administrator (Saudi National) @Siemens Mobility KSA